SZÁLLÍTÁSI SZERZŐDÉS mely létrejött egyrészről a Név: Dabas Város Önkormányzata Cím: 2370 Dabas, Szent István tér 1/b. Adószám: 15343006-2-04 Képviselő: Kőszegi Zoltán polgármester Pénzintézet: 64400099-10918018 Bankszámla: Alsónémedi és Vidéke Takarékszövetkezet Telefon: 06 29 561-200 Fax: 06 29 561-226
[email protected] E-mail: (továbbiakban Megrendelő), másrészről a Név: HOGE Kft. Cím: 1033 Budapest, Szőlőkert u.7. Adószám: 10246887-2-41 Cégjegyzékszám: 01-09-062505 Képviselő: Ónody Péter Pénzintézet: UniCredit Bank Bankszámla: 10900035-00000002-95890009 Telefon: 06-1/250-5163 Fax: 06-1/250-3963 E-mail:
[email protected] (továbbiakban Szállító) között a mai napon az alábbiakban meghatározott feltételekkel. PREAMBULUM A jelen szerződés tárgyában Megrendelő Eszközbeszerzés a „Dr. Halász Géza Szakorvosi Rendelőintézet fejlesztése” tárgyú projekthez kapcsolódóan elnevezéssel közbeszerzési eljárást folytatott le, melynek nyertese a Szállító. Szerződő Felek rögzítik, hogy a Szerződést a közbeszerzésekről szóló – többször módosított – 2003. évi CXXIX. törvény (továbbiakban: Kbt.) alapján, a fent hivatkozott közbeszerzési eljárásra tekintettel írják alá.
1. A szerződés tárgya 1.1. A szerződés tárgya az alább meghatározott eszközök (továbbiakban: áru) leszállítása, üzembe helyezése, illetve betanítása, valamint mindazon tevékenység elvégzése, mely a jelen szerződésben meghatározott.
II. Sterilizálás eszközei 1. 2. 3. 4. 5. 6. 7. 8.
Automata műszermosó Autokláv 4 STE Plazma steril Fólia hegesztő asztallal Átfúvó pisztoly Csomagoló asztal Tároló polc steril csomagoknak Ágytálmosó
Db 1 1 1 1 1 1 1 1
Szállító szerződéses feladatát képezi a fenti áruk teljes körű, hiány- és hibamentes leszállítása, illetve a jelen szerződésben meghatározott tevékenység (pl. üzembe helyezés) I. osztályú minőségben történő elvégzése, megfelelve a vonatkozó magyar és Európai Uniós szabványoknak, valamint a jelen szerződésben és mellékleteiben foglalt minden dokumentációnak és előírásnak, az alábbi dokumentumok szerint, melyek a szerződés részét képezik, attól függetlenül , hogy fizikailag a szerződés mellékleteként csatolásra kerülnek-e: a) A hatályos jogszabályok b) a jelen Szállítási Szerződés, c) a közbeszerzési eljárás Ajánlati Felhívása és Dokumentációja, beleértve a műszaki specifikációt, d) Szállító Ajánlata, a beárazott mennyiség kimutatásokkal és a tételek tartalmával együtt, e) egyéb, a Szerződést alkotó, annak részeként minősített további dokumentumok (a továbbiakban együttesen: Szerződés) A fent említett dokumentumok egymást kiegészítik, és kölcsönösen magyarázzák, de kétértelműség és eltérések esetén a Szerződés értelmezése szempontjából a szigorúbb előírást tartalmazó dokumentumban foglaltak a mértékadók. 2. Szerződéses ellenérték 2.1. A jelen szerződés tárgyát képező áru ellenértéke összesen 30,812,350,- Ft + Áfa, azaz harmincmillió-nyolcszáztizenkétezer-háromszázötven forint + Áfa. Az árban benne foglaltatik az áru szállítása, beállítása, üzembe helyezése és betanítása is, illetve valamennyi olyan költség, melyet az ajánlatkérési dokumentáció előír. Az ár a befejezési határidőre prognosztizált fix összegű ár, mely tartalmaz minden költséget, adó-, vám, illeték, járulék összeget, minden ráfordítást, ami a feladat elvégzésével kapcsolatban felmerülhet. A fent meghatározott ellenértéken felül más jogcímen számla nem nyújtható be, más fizetési kötelezettséget Megrendelő nem vállal. Az HUF pénznemben meghatározott egyösszegű ár nem kötött devizaárfolyamhoz, illetőleg egyéb ár módosulási feltétel sem alkalmazható. A szerződéses ár tartalmazza a teljes körű szállítást a megfelelő mennyiségben és minőségben, határidőre, a megadott helyszínekre, az árut védő megfelelő csomagolásban, az összeszereléssel, a beállítással és üzembe helyezéssel együtt. Szerződéses ár így különösen tartalmazza az ajánlatkérési dokumentációban található műszaki specifikációban meghatározott valamennyi berendezés, részegység, tartozék szállítását, az adott berendezés vonatkozásában meghatározott speciális feladat, illetve a szállítási szerződés-tervezetben a szállítás teljesítésével kapcsolatban meghatározott
feladat (pl. beépítési többletköltségek) elvégzését. A szerződéses ár tehát tartalmaz minden költséget, adó-, vám, illeték, járulék összeget, minden ráfordítást, ami a feladat elvégzésével kapcsolatban felmerülhet. 2.2. Megrendelő kötelezettséget vállal arra, hogy a jelen szerződés tárgyát képező áru üzembe helyezéséről felvett jegyzőkönyv aláírását követően 60 napon belül a szerződéses ellenértéket – számla ellenében – átutalja a Szállító UniCredit banknál vezetett 10900035-00000002-95890009 számú bankszámlájára. 2.3. Szállító a jelen szerződés tárgyát képező áru vonatkozásában tulajdonjogát a teljes vételár maradéktalan kiegyenlítéséig fenntartja. 2.4. Megrendelő fizetési késedelme esetén a Szállító jogában áll késedelmi kamatot felszámítani, melynek mértéke a jegybanki alapkamat. A kamatszámítás alapja a szerződéses bruttó ellenérték. 3. Szállítási feltételek és határidők – kiíró felvetett kérdésre adott válasza alapján 3.1. Szállító az árut az ajánlatkérési dokumentációban meghatározott teljesítési helyre szállítja le a Megrendelő részére, ahol a Megrendelő a Szállító képviselőjének közreműködésével szállítólevél alapján, tételesen átveszi a beépítést, speciális csatlakozást nem igénylő, üzembe helyezett árut. Az összes épületgépészeti és villamos kialakítás tekintetében a következő, Szállító Szerviz és Szolgáltatási csomag nyilatkozatában foglaltak az irányadóak: Az összes épületgépészeti és villamos kialakítás tekintetében ajánlattevő vállalja, hogy nyertessége esetén a szerződéskötést követő 2 héten belül részletes adatszolgáltatást nyújt az orvos-technológiai, gépész és villamos tervezők részére az általa szállítandó technológiai berendezések csatlakozási (hideg- és melegvíz, ioncserélt/RO-víz, csatorna, villamos, légtechnikai) igényeiről és az igényelt teljesítményről. Ezek alapján a szaktervezők elkészíthetik a végleges kiviteli terveket, melyek alapján a közeljövőben kiírásra kerülő építési közbeszerzési eljárás nyertese meg tudja valósítani a szükséges gépészeti, villamos átalakításokat. Ezzel elkerülhetővé válna az utólagos már kész épületen történő bontások és átalakítások kényszerű elvégzése. 3.2. Előteljesítés csak Megrendelő előzetes írásbeli hozzájárulásával lehetséges. Megrendelő Dabas város (Magyarország), 2370 Dabas, Bartók Béla út 61. szám alatt a Dr. Halász Géza Szakorvosi Rendelőintézet rekonstrukcióját végzi el, mely a jelen szerződés szerinti szállítás előfeltétele. Az építési kivitelezési szerződés teljesítésének tervezett határideje: 2011. I. ne. Tekintettel arra, hogy az eszközök a 2010-11-ben épülő létesítménybe kerülnek leszállításra várhatóan 2011. I. negyedévében, a szállítás legkorábbi időpontját Megrendelő az építmény készültségi állapotának függvényében a legkorábbi szállítási időpontot 90 nappal megelőzően írásban közli Szállítóval. A szállítás, próbaüzem stb. ütemezését a szerviz és szolgáltatási csomag szabályozza, az abban foglaltak az irányadóak. Szállítónak a szállítás fenti ütemezése okán felmerülő valamennyi díját és költségét az egyösszegű szállítási díj (ár) tartalmazza. A szállítási határidőt Megrendelő nem határozhatja meg úgy, hogy a végső átadás-átvétel időpontja (jótállási időszak kezdő napja) későbbi időpontra essen, mint 2011. augusztus 31.
3.3. Szállító beszerzi, a szerződés 1.1. pontjában meghatározott árut, helyszínre szállítja, a szükséges technológiai szereléseket elvégzi, és a berendezést üzembe helyezi. Gondoskodik a kezelőszemélyzet jegyzőkönyvvel igazolt oktatásáról, illetve mindazon feladat elvégzéséről, melyet a szerviz és szolgáltatási csomag előír. Annak érdekében, hogy a közmű hálózati bekötéseket, fogadó infrastruktúrát a szállítandó gép specifikációjának, kialakításának megfelelően készítse elő az épületet kivitelező vállalkozó, Megrendelő e tárgyban együttműködési kötelezettséget ír elő Szállító részére, az építési beruházást kivitelező vállalkozóval. 3.4. A szállítási határidőn belül a Szállító a szállítási készségről 3 nappal a szállítás előtt értesítést küld a Megrendelő részére, aki a fenti értesítés kézhezvételétől számított 48 órán belül visszaigazolja, hogy a szállítmányt milyen időpontban tudja fogadni, figyelembe véve a 3.2-es pontban foglaltakat is. 3.5. Szállító a jelen szerződés tárgyát képező árut a szállítás módjának megfelelő csomagolásban szállítja le. A szállítmányon a megfelelő kezelésre és tárolásra vonatkozó címkéket a szállító feltünteti. 3.6. A Szállító a jelen szerződés tárgyát képező áruhoz mellékeli a megfelelő szállítási okmányokat, a 16/2006. (III.27.) EüM rendelet által meghatározott minőségi tanúsítvány 1 példányát, valamint az önálló ismeretszerzésre alkalmas magyar nyelvű használati utasításokat, illetve mindazon dokumentumot, melyet a szerviz és szolgáltatási csomag előír. Az engedélyek beszerzése a Szállító feladata. 4. Az áru átvétele és tárolása 4.1. Az árut leszállítása, a fuvareszközből történő lerakása és rendeltetési helyen történő elhelyezése saját költségére és veszélyére Szállító kötelezettsége. 4.3. Az átadás-átvételt, a próbaüzemet, a rész-teljesítés, teljesítésigazolás kiállításának módját, időpontját, feltételeit a jelen szerződés elválaszthatatlan részét képező szerviz és szolgáltatási csomag(ok) tartalmazzák. 4.4. Az áru elvesztéséből vagy megrongálódásából, illetve bármely más okból eredő kárveszély a Szállítóról a Megrendelőre az üzembe helyezésről felvett jegyzőkönyv felek általi aláírásával száll át. 4.5. A ládabontást a rendeltetési helyen Szállító szakemberei végzik. A ládabontás során tapasztalt sérülésekről vagy hiányokról Szállító jegyzőkönyvet vesz fel. A megállapított hiányokat és sérüléseket Szállító az üzembe helyezésre előírt határidőn belül utánszállítással, vagy cserével saját költségére tartozik pótolni, illetve elvégezni. 5. Felszerelés, üzembe helyezés és betanítás 5.1. Az áru felszerelése és installálása, illetve üzembe helyezése a Szállító feladata, beleértve a 3.1 pontban foglaltakat is. 5.2. Szállító az áru felszerelését, illetve üzembe helyezését a szerviz és szolgáltatási csomagban foglaltak szerint végzi el.
5.3. Szerződő felek az áruk üzembe helyezéséről és a berendezések próbaüzemének sikeres befejezéséről jegyzőkönyvet vesznek fel, melynek keltétől számít az áru megrendelő részére történő műszaki átadása, valamint az áru jótállási ideje is. A jegyzőkönyv felvétel napján állítja ki Megrendelő a rész-teljesítésigazolást. 5.4. A jegyzőkönyv aláírására jogosult személyek, beosztásuk és elérhetőségük 5.4.1. Szállító részéről: Madács László, szervizvezető telefon: 0630/982-3215 , fax: 06-1/250-3963 5.4.2. Megrendelő részéről: Lovassy Ádám, telefon: 70/313-9996, fax: 06 29 561-226 5.5. Szállító köteles az üzembe helyezés során az állag-, vagyon és kapcsolódó életvédelem biztonságának garantálására, az esetlegesen Megrendelőnek okozott károk megtérítésével együtt. Szállító a nem szakszerű munkavégzésből eredő károkért teljes körű felelősséggel – költségátvállalás mellett – felel. 5.6. Szállító a szállítandó berendezés minőségét az érvényes rendeletek és szabványok szerint vállalja, és azt a szállítás, vagy a beépítés előtt minőségtanúsítvánnyal igazolja, azt átadja Megrendelőnek. 5.7. Szállító az áru üzemeltetéséhez a Megrendelő által kijelölt személyzet részére a szerviz és szolgáltatási csomagban foglaltak szerint oktatást végez. 5.8. Szállító a jelen szerződésben rögzített teljesítéseit határidőben teljesíti, amennyiben az áru üzembe helyezését, a próbaüzem sikeres befejezését a jelen szerződésben foglalt határidőre elvégzi. 6. Szerződést biztosító mellékkötelezettségek, jótállás, szavatosság, szervízelés Teljesítési biztosíték 6.1. Felek megállapodnak abban, hogy a Szállító a szerződés aláírásáig a nettó szerződéses összeg 3 %-ára teljesítési biztosítékot ad a közbeszerzésekről szóló 2003. évi CXXIX. törvény (Kbt.) 53. § (6) bekezdés a) pontja szerint. A teljesítési biztosíték abban az esetben hívható le, ha a Szállító szerződésszegést követ el. A teljesítési biztosítéknak a hiány- és hibamentes teljesítés napját követően 12 hónapig kell rendelkezésre állnia. 6.2. Amennyiben a teljesítési biztosíték nyújtása bankgarancia biztosításával, vagy biztosítási szerződés alapján kiállított és a biztosító készfizető kezességvállalását tartalmazó kötelezvénnyel történt, úgy az akkor megfelelő, ha a nettó szerződéses összeg legalább 3 %-ára vonatkozik, - korlátozás nélküli és visszavonhatatlan; - 5 banki munkanap alatt igénybe vehető, - futamideje (érvényessége) a szerződésben vállalt szállítás sikeres teljesítését követő 12 hónap. 6.3. Fentieken túlmenően a teljesítési biztosítékra vonatkozó levélnek tartalmaznia kell azt, hogy a bank, illetőleg a biztosító kötelezi magát, hogy a Megrendelő első írásbeli felszólítására, a Szállító esetleges kifogásolását figyelmen kívül hagyva, a jogviszony
vizsgálata nélkül, a bank, illetőleg a biztosító saját kötelezettsége alapján azonnal kifizeti a Megrendelőnek a Megrendelő által írásban megjelölt összeget. Késedelmi kötbér, hibás teljesítési kötbér, meghiúsulási kötbér 6.4. Szállító késedelmes teljesítése esetén késedelmi kötbért köteles fizetni, melynek mértéke napi 200.000 Ft, legfeljebb azonban összesen a nettó szerződéses érték 20 %-a. 6.5. Szállító hibás teljesítése esetén kötbért köteles fizetni, a hiba Megrendelő által elismert kiküszöböléséig terjedő időre, melynek mértéke napi 200.000 Ft, legfeljebb azonban összesen a nettó szerződéses érték 20 %-a. 6.6. Szállító meghiúsulás esetén meghiúsulási kötbért köteles fizetni, melynek összege a meghiúsult teljesítés nettó összegének 20 %-a, melybe a teljesítési biztosíték – még érvényesíthető része - beszámításra kerül. Amennyiben a Szállítói késedelem a 15 napot meghaladja, és Megrendelő írásbeli felszólítására a Szállító 15 napon belül nem ad a Megrendelő számára elfogadható írásbeli tájékoztatást a késedelem okáról és a késedelem megszüntetésének módjáról, vagy a Szállító az ilyen tájékoztatást megadja, de azt a Megrendelő nem fogadja el, a Megrendelő egyoldalúan jogosult jelen szerződéstől elállni. Jótállás, jótálláson túli szervizelés, szavatosság, felelősség 6.7. Szállító a jelen szerződés alapján leszállított árura üzembe helyezés napjától számított 2 év időtartamban, a gyári garancia-feltételek szerinti teljes körű jótállást vállal. 6.8. Szállító a készülék üzembe helyezésekor üzembe helyezési jegyzőkönyvet készít, amely tartalmazza a telepített eszköz és gyári számmal rendelkező részegységei azonosító számát és a vonatkozó garanciaidő hosszát. 6.9. A garanciavállalás nem vonatkozik a készülékkel szállított kopó- és fogyóanyagokra, tartozékokra, azonban az üzembe helyezést követő sikeres próbaüzem esetén az ár tartalmazza a teljes körű karbantartást a vonatkozó közbeszerzési eljárásban meghatározott jótállás minimális időtartamaként meghatározott időszak alatt a teljes rendszerre, alkatrészekkel együtt, beleértve a kiszállást és munkadíjakat is. 6.10. Amennyiben az áru meghibásodott vagy hiányos, a Szállító haladéktalanul köteles azt kijavítani, illetve a felmerült hiányt pótolni. 6.11. Amennyiben a jótállási idő alatt fellépő hiba nem javítható, a Megrendelő követelheti az áru, illetve a meghibásodott alkatrész haladéktalan kicserélését. A le- és felszerelésről, valamint a szállításról a Szállító gondoskodik saját költségén. Kivételt képeznek azon kopó- és fogyóanyagok, melyek nem tartoznak a karbantartás körébe. 6.12. Írásos hibabejelentés esetén Szállító annak kézhezvételét követő legfeljebb a szerviz és szolgáltatási csomagban foglalt időtartamon belül köteles a helyszínre kiszállni, és dokumentált hibafeltáró vizsgálatot tartani, valamint a hiba elhárításáról intézkedni. Szállító munkalapon rögzíti azokat az intézkedéseket, amelyeket a hiba kiküszöbölése érdekében megtett.
6.13. Szállító vállalja, hogy a jótállási idő lejártát követően külön szerződésben rögzített feltételek mellett, térítés ellenében ellátja az áru szervizelését. A Szállító az áruhoz szükséges tartalék-alkatrészeket az üzembe helyezéstől számított minimum 8 évig biztosítja. 7. 7.1.
Szoftverrendelkezések Szállító a jelen szerződés tárgyát képező áruval együtt rendelkezésre bocsátott szoftverek felhasználási jogait korlátozás nélküli időtartamra át nem ruházható, illetve nem kizárólagos jelleggel adja át Megrendelőnek.
7.2.
Az áruval együtt leszállított szoftvereket a Megrendelő a leszállított áruval együtt annak működtetése céljából jogosult változatlan formában és a műszaki leírásban megnevezett célra használni.
7.3.
A szoftvereket és az ehhez tartozó dokumentációt a Megrendelő harmadik fél részére kizárólag az eszköz tulajdonjogának átruházása esetén adhatja át, amennyiben az átruházás egyéb feltételei fennállnak. Elidegenítés esetén a szoftver rendelkezéseket azonos tartalommal Megrendelő köteles előírni a vevő részére.
7.4.
A szoftverek használati díját a vételár tartalmazza. Szállító kijelenti, hogy a szállított szoftverekkel kapcsolatos rendelkezési jog harmadik féltől mentes.
7.5.
Megrendelő a szoftvereket nem másolhatja le, nem fejlesztheti tovább, nem fejlesztheti vissza, illetve nem törölheti azokat.
7.6.
A leszállított áru teljesítményének, illetve teljesítőképességének növelése érdekében az azzal együtt szállított szoftver módosítása, illetve bővítése a szerviz és szolgáltatási csomagban foglaltak szerint történhet.
8.
Kapcsolattartás A szerződő felek közötti kapcsolattartás írásban történik. A szerződő felek közötti kapcsolattartás során fel kell tüntetni a szerződés megnevezését, az azonosító számát, és azt postán, faxon, e-mailen kell elküldeni, vagy személyesen kézbesíteni az alábbi címekre: A Megrendelő részére: név: Lovassy Ádám cím: 2370 Dabas, Szent István tér 1/b. telefon, fax, e-mail: 06 29 561-200, 06 29 561-226,
[email protected] A Szállító részére: név: Madács László cím: 1033 Budapest, Szőlőkert u.7. telefon, fax, e-mail: 0630/982-3215; 06-1/250-3963;
[email protected]
9.
Vegyes rendelkezések 9.1.
Felek megállapodnak abban, hogy a szerződés keretében átvett dokumentációkat csak a jelen szerződés alapján, a vállalt feladat teljesítése érdekében használják fel.
9.2.
Felek megállapodnak, hogy a szerződésben meghatározottakon kívül, egyik fél sem kezdeményez – a másik fél írásbeli tájékoztatása nélkül – olyan folyamatot, vagy
tevékenységet, amelyik a másik félnek a szerződésben nem szabályozott költséget, vagy többletköltséget okozhat. 9.3.
Szerződő felek mentesülnek a jelen szerződésből fakadó kötelezettségeik nem-, vagy részleges nem-teljesítésével kapcsolatos felelősség alól, ha az a szerződés hatályának beálltát követően felmerülő ellenállhatatlan erő következménye. A vis maior helyzet bekövetkezéséről, illetve megszűnéséről szerződő felek egymást haladéktalanul értesítik, és a megszűnést követően mindent megtesznek a szerződésszerű teljesítés érdekében.
9.4.
A jelen szerződés csak a szerződő felek közös megegyezésével, a vonatkozó jogszabályok által lehetővé tett módon és feltételek fennállása esetén módosíthatók. A szerződés módosításának írásbeli formában kell történnie, a Kbt. szerződés módosításra vonatkozó rendelkezéseivel összhangban.
9.5.
A jelen szerződésből eredő jogvitákat szerződő felek megkísérlik békés úton rendezni. Amennyiben ez nem vezet eredményre, szerződő felek a jogvitájuk elbírálása céljából kikötik a Dabas Városi Bíróság kizárólagos illetékességét. Amennyiben a per a pertárgy értékére tekintettel megyei bíróság hatáskörébe tartozna, úgy a Pest Megyei Bíróság kizárólagosan illetékes.
9.6.
A jelen szerződésben nem szabályozott kérdésekben a Ptk. és egyéb hatályos jogszabályok rendelkezései az irányadóak.
9.7.
Szállító vállalja, hogy dolgozói, alkalmazottai balesetbiztosítással rendelkeznek.
9.8.
Szerződő Felek kifejezetten rögzítik, hogy amennyiben a Szerződés bármely kikötése érvénytelennek vagy hatálytalannak bizonyulna, az a Szerződés egyéb rendelkezéseit nem érinti. Szerződő Felek megállapodnak, hogy amennyiben az érvénytelenség, hatálytalanság okát orvosolni lehet, úgy mindent megtesznek az adott szerződésrész érvényben, illetve hatályban tartása érdekében, illetve azt olyan érvényes vagy hatályos rendelkezéssel pótolják, amely a legjobban megfelel az adott szerződésrész szellemének és gazdasági célkitűzéseinek. A szerződő Fél nem köteles e pontban meghatározott célkitűzés érvényesítésére, ha súlyos szerződésszegés miatt a szerződés fennmaradása már nem áll a szerződő Fél érdekében.
9.9.
A szerződő Felek megállapodnak abban, ha cégszerűen aláírt levelet, vagy okiratot a jelen szerződésben megadott székhely és/vagy levelezési címre ajánlottan elküldik, azt a levél átvételének napján, de legkésőbb a feladást követő 8. napon kézbesítettnek tekintik. Tértivevénnyel elküldött levél esetén a visszaérkezett tértivevényen igazolt átvételi napon tekintik kézbesítettnek. Amennyiben a tértivevény a feladást követő 8 napon belül nem érkezik vissza, úgy a levelet a 8. napon kézbesítettnek tekintik.
Felek az adózás rendjéről szóló 2003. évi XCII. törvény 36/A. §-ának betartására 9.10. és betartatására is kötelezettséget vállalnak. A számla vonatkozásában be kell nyújtani: a) 30 napnál nem régebbi nemlegesnek minősülő együttes adóigazolást (figyelem: az együttes adóigazolásnak a tényleges kifizetés időpontjában 30 napnál nem régebbinek kell lennie), vagy b) nyilatkozatot arról, hogy együttes adóigazolást azért nem nyújtott be, mert szerepel a köztartozás mentes adózói adatbázisban.
9.11. Szállító feltétlenül és visszavonhatatlanul hozzájárul ahhoz, hogy megrendelő a Kbt. 17/C. §-ban és egyéb, a Kbt-ben meghatározott nyilvánosság biztosításával kapcsolatosan előírt kötelezettségének eleget tehessen. 9.12.
Jelen szerződés pályázati támogatásból valósul meg.
Pályázat neve: „Kistérségi járóbeteg szakellátás fejlesztése a Közép-Magyarországi régióban” (Kódszám: KMOP-4.3.2.) Projekt megnevezése: „Dr. Halász Géza Szakorvosi Rendelőintézet fejlesztése” Amennyiben a pályázati támogatást Megrendelő hibáján kívüli okból részben, vagy egészben nem sikerül lehívni, úgy a jelen szerződést Megrendelő kártérítési, kártalanítási és egyéb térítési kötelezettség nélkül felmondhatja, illetőleg a szerződés módosítását kezdeményezheti. Megrendelő felmondása esetén Szállító az elvégzett munkájával arányosan jogosult díjazásra és költségei megtérítésére, a közbeszerzési ajánlata szerint, a szerződéskötéstől a felmondásig végrehajtott Szállítói teljesítmény alapján. 9.13. A Kbt. 99. § (1) bekezdésében foglaltak alapján a 305. § (4) bekezdése szerinti feltételek teljesülésének esetére Megrendelő az alábbiakat jelenti ki: Dabas Város Önkormányzata kijelenti, hogy felhatalmazza a jelen szerződésben meghatározott pénzintézetét, hogy a jelen szerződében meghatározott fizetési számlájára a Szállító a Megrendelő által igazolt szerződésszerű teljesítés esetén, a Kbt. 305. § (3) bekezdés szerinti határidő eredménytelen elteltét követően – a Megrendelő jelen felhatalmazó nyilatkozata alapján – beszedési megbízást nyújtson be. Jelen szerződést felek elolvasás és értelmezés után, mint akaratukkal mindenben 9.14. megegyezőt cégszerű aláírásukkal látták el. Dabas, 2010. május 6. …………………………….. Megrendelő
………………………………………… Szállító